Terms & Conditions

1.1    “Client” means the person/s buying the Materials (and/or hiring Equipment) as specified in any invoice, document or order, and if there is more than one Client is a reference to each Client jointly and severally.
1.2    “Materials” means all Materials or Works supplied by the Supplier to the Client at the Client’s request from time to time (where the context so permits the terms ‘Materials’ or ‘Works’ shall be interchangeable for the other).
1.3    “Equipment” means all Equipment including any accessories supplied on hire by the Supplier to the Client (and where the context so permits shall include any supply of Works). The Equipment shall be as described on the invoices, quotation, authority to hire, or any other work authorisation form provided by the Supplier to the Client.
1.4    “Price” means the Price payable for the Materials and/or Equipment hire as agreed between the Supplier and the Client in accordance with clause 4 below.

2.    Acceptance

2.1    The Client is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Client places an order for or accepts delivery of the Materials/Equipment.
2.2    These terms and conditions may only be amended with the Supplier’s consent in writing and shall prevail to the extent of any inconsistency with any other document or agreement between the Client and the Supplier.

3.    Change in Control

3.1    The Client shall give the Supplier not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client and/or any other change in the Client’s details (including but not limited to, changes in the Client’s name, address, contact phone or fax number/s, or business practice). The Client shall be liable for any loss incurred by the Supplier as a result of the Client’s failure to comply with this clause.

4.    Price and Payment

4.1    At the Supplier’s sole discretion the Price shall be either:
(a)    as indicated on any invoice provided by the Supplier to the Client; or
(b)    the Price as at the date of delivery of the Materials/Equipment according to the Supplier’s current price list; or
(c)    the Supplier’s quoted price (subject to clause 4.2) which will be valid for the period stated in the quotation or otherwise for a period of thirty (30) days.
4.2    The Supplier reserves the right to change the Price:
(a)    if a variation to the Materials which are to be supplied is requested; or
(b)    if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or
(c)    where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, poor weather conditions, limitations to accessing the site, availability of machinery, safety considerations, prerequisite work by any third party not being completed, change of design, or hidden pipes and wiring in walls etc) which are only discovered on commencement of the Works; or
(d)    in the event of increases to the Supplier in the cost of labour or materials which are beyond the Supplier’s control.
4.3    At the Supplier’s sole discretion a non-refundable deposit may be required.
4.4    Time for payment for the Materials/Equipment being of the essence, the Price will be payable by the Client on the date/s determined by the Supplier, which may be:
(a)    on delivery of the Materials/Equipment;
(b)    before delivery of the Materials/Equipment;
(c)    by way of instalments/progress payments in accordance with the Supplier’s payment schedule;
(d)    thirty (30) days following the end of the month in which a statement is posted to the Client’s address or address for notices;
(e)    the date specified on any invoice or other form as being the date for payment; or
(f)    failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Client by the Supplier.
4.5    Payment may be made by cash, cheque, bank cheque, electronic/on-line banking, credit card (plus a surcharge of up to 2.5% of the Price), or by any other method as agreed to between the Client and the Supplier.
4.6    Unless otherwise stated the Price does not include GST. In addition to the Price the Client must pay to the Supplier an amount equal to any GST the Supplier must pay for any supply by the Supplier under this or any other agreement for the sale of the Materials/hire of the Equipment. The Client must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Client pays the Price. In addition the Client must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.

5.    Delivery of Materials/Equipment

5.1    Subject to clause 5.2 it is the Supplier’s responsibility to ensure that the Works start as soon as it is reasonably possible.
5.2    The Works commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that the Supplier claims an extension of time (by giving the Client written notice) where completion is delayed by an event beyond the Supplier’s control, including but not limited to any failure by the Client to:
(a)    make a selection; or
(b)    have the site ready for the Works; or
(c)    notify the Supplier that the site is ready.
5.3    Delivery (“Delivery”) of the Materials/Equipment is taken to occur at the time that:
(a)    the Client or the Client’s nominated carrier takes possession of the Materials/Equipment at the Supplier’s address; or
(b)    the Supplier (or the Supplier’s nominated carrier) delivers the Materials/Equipment to the Client’s nominated address even if the Client is not present at the address.
5.4    At the Supplier’s sole discretion the cost of delivery is either included in the Price or is in addition to the Price.
5.5    The Client must take delivery by receipt or collection of the Materials/Equipment whenever either is tendered for delivery. In the event that the Client is unable to take delivery of the Materials/Equipment as arranged then the Supplier shall be entitled to charge a reasonable fee for redelivery of the Materials/Equipment and/or the storage of the Materials.
5.6    The Supplier may deliver the Materials/Equipment in separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.
5.7    Any time or date given by the Supplier to the Client is an estimate only. The Client must still accept delivery of the Materials/Equipment even if late and the Supplier will not be liable for any loss or damage incurred by the Client as a result of the delivery being late.

6.    Risk
6.1    Risk of damage to or loss of the Materials passes to the Client on Delivery and the Client must insure the Materials on or before Delivery.
6.2    If any of the Materials are damaged or destroyed following delivery but prior to ownership passing to the Client, the Supplier is entitled to receive all insurance proceeds payable for the Materials. The production of these terms and conditions by the Supplier is sufficient evidence of the Supplier’s rights to receive the insurance proceeds without the need for any person dealing with the Supplier to make further enquiries.
6.3    If the Client requests the Supplier to leave Materials outside the Supplier’s premises for collection or to deliver the Materials to an unattended location then such Materials shall be left at the Client’s sole risk.
6.4    Where the Supplier is required to install the Materials the Client warrants that the structure of the premises or equipment in or upon which these Materials are to be installed or erected is sound and will sustain the installation and work incidental thereto and the Supplier shall not be liable for any claims, demands, losses, damages, costs and expenses howsoever caused or arising in connection with the installation and work incidental thereto.
6.5    The Client acknowledges and agrees that no persons other than those authorised or employed by the Supplier are to walk on the treated roof surface for a period of twenty-one (21) days after completion of the job and at no time are any persons permitted to be in the areas of the works.  The Supplier shall not be liable for any loss, damages, injuries, or costs however arising resulting from the Client’s failure to comply with this clause.
6.6    Where the Client has supplied materials for the Supplier to complete the Works, the Client acknowledges that he accepts responsibility for the suitability of purpose, quality and any faults inherent in the materials. The Supplier shall not be responsible for any defects in the Works, any loss or damage to the Materials (or any part thereof), howsoever arising from the use of materials supplied by the Client.
6.7    Any advice, recommendation, information, assistance or service provided by the Supplier in relation to Materials or Works supplied is given in good faith, is based on the Suppliers own knowledge and experience and shall be accepted without liability on the part of the Supplier and it shall be the responsibility of the Client to confirm the accuracy and reliability of the same in light of the use to which the Client makes or intends to make of the Materials or Works.

7.    Access 

7.1    The Client shall ensure that the Supplier has clear and free access to the work site at all times to enable them to undertake the Works. The Supplier shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of the Supplier.

8.    Underground Locations  

8.1    Prior to the Supplier commencing any work the Client must advise the Supplier of the precise location of all underground services on the site and clearly mark the same. The underground mains & services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on site.
8.2    Whilst the Supplier will take all care to avoid damage to any underground services the Client agrees to indemnify the Supplier in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 8.1.

9.    Client’s Responsibilities

9.1    The Client acknowledges that in the event asbestos or any other toxic substances are discovered at the worksite that it is their responsibility to ensure the safe removal of the same. The Client further agrees to indemnify the Supplier against any costs incurred by the Supplier as a consequence of such discovery. Under no circumstances will the Supplier handle removal of asbestos product.
9.2    The Client acknowledges that it is their responsibility to ensure that all Materials, plant or equipment which the Supplier is required to install (or to connect any of its Materials to) are of the correct type, size, rating, standard, quality, colour and finish, conform with all relevant Australian standards and local statutory requirements, and are as specified in the specifications, drawings and plans upon which the Supplier based the quotation on and therefore, the Client agrees to indemnify the Supplier against any costs incurred by the Supplier in rectifying such errors if required.
9.3    The Supplier is not responsible for the removal of rubbish from or clean-up of the building/constructions site/s.  This is the responsibility of the Client or the Client’s agent.
9.4    It is further agreed that:
(a)    the Client will supply temporary lighting, toilet, eating and first aid facilities if required; and
(b)    the Client will advise all amenity locations (including without limitation, water, gas, electricity, telephone or any other underground amenity) to the Supplier prior to delivery.

10.    Title To Materials

10.1    The Supplier and the Client agree that ownership of the Materials shall not pass until:
(a)    the Client has paid the Supplier all amounts owing to the Supplier; and
(b)    the Client has met all of its other obligations to the Supplier.
10.2    Receipt by the Supplier of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.
10.3    It is further agreed that:
(a)    until ownership of the Materials passes to the Client in accordance with clause 10.1 that the Client is only a bailee of the Materials and must return the Materials to the Supplier on request.
(b)    the Client holds the benefit of the Client’s insurance of the Materials on trust for the Supplier and must pay to the Supplier the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed.  
(c)    the Client must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Client sells, disposes or parts with possession of the Materials then the Client must hold the proceeds of any such act on trust for the Supplier and must pay or deliver the proceeds to the Supplier on demand.
(d)    the Client should not convert or process the Materials or intermix them with other Materials but if the Client does so then the Client holds the resulting product on trust for the benefit of the Supplier and must sell, dispose of or return the resulting product to the Supplier as it so directs.
(e)    the Client irrevocably authorises the Supplier to enter any premises where the Supplier believes the Materials are kept and recover possession of the Materials.
(f)    the Supplier may recover possession of any Materials in transit whether or not delivery has occurred.
(g)    the Client shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of the Supplier.
(h)    the Supplier may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not passed to the Client.

11.    Personal Property Securities Act 2009 (“PPSA”)

11.1    In this clause financing statement, financing change statement, security agreement, and security interest has the meaning given to it by the PPSA.
11.2    Upon assenting to these terms and conditions in writing the Client acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of the PPSA and creates a security interest in all Materials/Equipment that has previously been supplied and that will be supplied in the future by the Supplier to the Client.
11.3    The Client undertakes to:
(a)    promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Supplier may reasonably require to;
(i)    register a financing statement or financing change statement in relation to a security interest on the Personal Property Securities Register;
(ii)    register any other document required to be registered by the PPSA; or
(iii)    correct a defect in a statement referred to in clause 11.3(a)(i) or 11.3(a)(ii);
(b)    indemnify, and upon demand reimburse, the Supplier for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by the PPSA or releasing any Materials/Equipment charged thereby;
(c)    not register a financing change statement in respect of a security interest without the prior written consent of the Supplier;
(d)    not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials/Equipment in favour of a third party without the prior written consent of the Supplier;
(e)    immediately advise the Supplier of any material change in its business practices of selling Materials which would result in a change in the nature of proceeds derived from such sales.
11.4    The Supplier and the Client agree that sections 96, 115 and 125 of the PPSA do not apply to the security agreement created by these terms and conditions.
11.5    The Client waives their rights to receive notices under sections 95, 118, 121(4), 130, 132(3)(d) and 132(4) of the PPSA.
11.6    The Client waives their rights as a grantor and/or a debtor under sections 142 and 143 of the PPSA.
11.7    Unless otherwise agreed to in writing by the Supplier, the Client waives their right to receive a verification statement in accordance with section 157 of the PPSA.
11.8    The Client must unconditionally ratify any actions taken by the Supplier under clauses 11.3 to 11.5.
11.9    Subject to any express provisions to the contrary nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions of the PPSA.

12.    Security and Charge

12.1    In consideration of the Supplier agreeing to supply the Materials/Equipment, the Client charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Client either now or in the future, to secure the performance by the Client of its obligations under these terms and conditions (including, but not limited to, the payment of any money).
12.2    The Client indemnifies the Supplier from and against all the Supplier’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising the Supplier’s rights under this clause.
12.3    The Client irrevocably appoints the Supplier and each director of the Supplier as the Client’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 12 including, but not limited to, signing any document on the Client’s behalf.

13.    Defects, Warranties and Returns, Competition and Consumer Act 2010 (CCA)

13.1    The Client must inspect the Materials/Equipment on delivery and must within seven (7) days of delivery notify the Supplier in writing of any evident defect/damage, shortage in quantity, or failure to comply with the description or quote. The Client must notify any other alleged defect in the Materials/Equipment as soon as reasonably possible after any such defect becomes evident. Upon such notification the Client must allow the Supplier to inspect the Materials/Equipment.
13.2    Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (Non-Excluded Guarantees).
13.3    The Supplier acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.
13.4    Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, the Supplier makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Equipment. The Supplier’s liability in respect of these warranties is limited to the fullest extent permitted by law.
13.5    If the Client is a consumer within the meaning of the CCA, the Supplier’s liability is limited to the extent permitted by section 64A of Schedule 2.
13.6    If the Supplier is required to replace the Materials under this clause or the CCA, but is unable to do so, the Supplier may refund any money the Client has paid for the Materials.
13.7    If the Client is not a consumer within the meaning of the CCA, the Supplier’s liability for any defect or damage in the Materials is:
(a)    limited to the value of any express warranty or warranty card provided to the Client by the Supplier at the Supplier’s sole discretion;
(b)    limited to any warranty to which the Supplier is entitled, if the Supplier did not manufacture the Materials;
(c)    otherwise negated absolutely.
13.8    Subject to this clause 13, returns will only be accepted provided that:
(a)    the Client has complied with the provisions of clause 13.1; and
(b)    the Supplier has agreed that the Materials are defective; and
(c)    the Materials are returned within a reasonable time at the Client’s cost (if that cost is not significant); and
(d)    the Materials are returned in as close a condition to that in which they were delivered as is possible.
13.9    Notwithstanding clauses 13.1 to 13.8 but subject to the CCA, the Supplier shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:
(a)    the Client failing to properly maintain or store any Materials/Equipment;
(b)    the Client using the Materials/Equipment for any purpose other than that for which they were designed;
(c)    the Client continuing the use of the Materials/Equipment after any defect became apparent or should have become apparent to a reasonably prudent operator or user;
(d)    the Client failing to follow any instructions or guidelines provided by the Supplier;
(e)    fair wear and tear, any accident, or act of God.
13.10    In the case of second hand Materials, unless the Client is a consumer under the CCA, the Client acknowledges that it has had full opportunity to inspect the second hand Materials prior to delivery and accepts them with all faults and that to the extent permitted by law no warranty is given by the Supplier as to the quality or suitability for any purpose and any implied warranty, statutory or otherwise, is expressly excluded. The Client acknowledges and agrees that the Supplier has agreed to provide the Client with the second hand Materials and calculated the Price of the second hand Materials in reliance of this clause 13.10.
13.11    The Supplier may in its absolute discretion accept non-defective Materials for return in which case the Supplier may require the Client to pay handling fees of up to twenty percent (20%) of the value of the returned Materials plus any freight costs.
13.12    Notwithstanding anything contained in this clause if the Supplier is required by a law to accept a return then the Supplier will only accept a return on the conditions imposed by that law.

14.    Intellectual Property

14.1    Where the Supplier has designed, drawn or developed Materials/Equipment for the Client, then the copyright in any designs and drawings and documents shall remain the property of the Supplier.
14.2    The Client warrants that all designs, specifications or instructions given to the Supplier will not cause the Supplier to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify the Supplier against any action taken by a third party against the Supplier in respect of any such infringement.
14.3    The Client agrees that the Supplier may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings or Materials which the Supplier has created for the Client.

15.    Default and Consequences of Default

15.1    Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at the Supplier’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.
15.2    If the Client owes the Supplier any money the Client shall indemnify the Supplier from and against all costs and disbursements incurred by the Supplier in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, the Supplier’s collection agency costs, and bank dishonour fees).
15.3    Without prejudice to any other remedies the Supplier may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions the Supplier may suspend or terminate the supply of Materials/Equipment to the Client. The Supplier will not be liable to the Client for any loss or damage the Client suffers because the Supplier has exercised its rights under this clause.
15.4    Without prejudice to the Supplier’s other remedies at law the Supplier shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to the Supplier shall, whether or not due for payment, become immediately payable if:
(a)    any money payable to the Supplier becomes overdue, or in the Supplier’s opinion the Client will be unable to make a payment when it falls due;
(b)    the Client becomes insolvent, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
(c)    a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.

16.    Compliance with Laws  

16.1    The Client and the Supplier shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Works.
16.2    The Client shall obtain (at the expense of the Client) all licenses and approvals that may be required for the Works.
16.3    The Client agrees that the site will comply with any occupational health and safety laws relating to building/construction sites and any other relevant safety standards or legislation.

17.    Cancellation

17.1    The Supplier may cancel any contract to which these terms and conditions apply or cancel delivery of Materials/Equipment at any time before the Materials/Equipment are due to be delivered by giving written notice to the Client. On giving such notice the Supplier shall repay to the Client any money paid by the Client for the Materials/Equipment. The Supplier shall not be liable for any loss or damage whatsoever arising from such cancellation.
17.2    In the event that the Client cancels delivery of the Materials/Equipment the Client shall be liable for any and all loss incurred (whether direct or indirect) by the Supplier as a direct result of the cancellation (including, but not limited to, any loss of profits).
17.3    Cancellation of orders for Materials/Equipment made to the Client’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.

18.    Dispute Resolution

18.1    If a dispute arises between the parties to this contract then either party shall send to the other party a notice of dispute in writing adequately identifying and providing details of the dispute. Within fourteen (14) days after service of a notice of dispute, the parties shall confer at least once, to attempt to resolve the dispute. At any such conference each party shall be represented by a person having authority to agree to a resolution of the dispute. In the event that the dispute cannot be so resolved either party may by further notice in writing delivered by hand or sent by certified mail to the other party refer such dispute to arbitration.  Any arbitration shall be:
(a)    referred to a single arbitrator to be nominated by the President of the Institute of Arbitrators Australia; and
(b)    conducted in accordance with the Institute of Arbitrators Australia Rules for the Conduct of Commercial Arbitration.

19.    Privacy Act 1988

19.1    The Client agrees for the Supplier to obtain from a credit reporting agency a credit report containing personal credit information about the Client in relation to credit provided by the Supplier.
19.2    The Client agrees that the Supplier may exchange information about the Client with those credit providers either named as trade referees by the Client or named in a consumer credit report issued by a credit reporting agency for the following purposes:
(a)    to assess an application by the Client; and/or
(b)    to notify other credit providers of a default by the Client; and/or
(c)    to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit providers; and/or
(d)    to assess the creditworthiness of the Client.
The Client understands that the information exchanged can include anything about the Client’s creditworthiness, credit standing, credit history or credit capacity that credit providers are allowed to exchange under the Privacy Act 1988.
19.3    The Client consents to the Supplier being given a consumer credit report to collect overdue payment on commercial credit (Section 18K(1)(h) Privacy Act 1988).
19.4    The Client agrees that personal credit information provided may be used and retained by the Supplier for the following purposes (and for other purposes as shall be agreed between the Client and Supplier or required by law from time to time):
(a)    the provision of Materials/Equipment; and/or
(b)    the marketing of Materials/Equipment by the Supplier, its agents or distributors; and/or
(c)    analysing, verifying and/or checking the Client’s credit, payment and/or status in relation to the provision of Materials/Equipment; and/or
(d)    processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Client; and/or
(e)    enabling the daily operation of Client’s account and/or the collection of amounts outstanding in the Client’s account in relation to the Materials/Equipment.
19.5    The Supplier may give information about the Client to a credit reporting agency for the following purposes:
(a)    to obtain a consumer credit report about the Client;
(b)    allow the credit reporting agency to create or maintain a credit information file containing information about the Client.
19.6    The information given to the credit reporting agency may include:
(a)    personal particulars (the Client’s name, sex, address, previous  addresses, date of birth, name of employer and driver’s licence number);
(b)    details concerning the Client’s application for credit or commercial credit and the amount requested;
(c)    advice that the Supplier is a current credit provider to the Client;
(d)    advice of any overdue accounts, loan repayments, and/or any outstanding monies owing which are overdue by more than sixty (60) days, and for which debt collection action has been started;
(e)    that the Client’s overdue accounts, loan repayments and/or any outstanding monies are no longer overdue in respect of any default that has been listed;
(f)    information that, in the opinion of the Supplier, the Client has committed a serious credit infringement (that is, fraudulently or shown an intention not to comply with the Client’s credit obligations);
(g)    advice that cheques drawn by the Client for one hundred dollars ($100) or more, have been dishonoured more than once;
(h)    that credit provided to the Client by the Supplier has been paid or otherwise discharged.

20.    Equipment Hire

20.1    Equipment shall at all times remain the property of the Supplier and is returnable on demand by the Supplier. In the event that Equipment is not returned to the Supplier in the condition in which it was delivered the Supplier retains the right to charge the Client the full cost of repairing the Equipment. In the event that Equipment is not returned at all the Supplier shall have right to charge the Client the full cost of replacing the Equipment.
20.2    The Client shall;
(a)    keep the Equipment in their own possession and control and shall not assign the benefit of the Equipment nor be entitled to a lien over the Equipment.
(b)    not alter or make any additions to the Equipment including but without limitation altering, make any additions to, defacing or erasing any identifying mark, plate or number on or in the Equipment or in any other manner interfere with the Equipment.
(c)    keep the Equipment, complete with all parts and accessories, clean and in good order as delivered, and shall comply with any maintenance schedule as advised by the Supplier to the Client.
20.3    The Client accepts full responsibility for the safekeeping of the Equipment and the Client agrees to insure, or self insure, the Supplier’s interest in the Equipment and agrees to indemnify the Supplier against physical loss or damage including, but not limited to, the perils of accident, fire, theft and burglary and all other usual risks and will effect adequate Public Liability Insurance covering any loss, damage or injury to property or persons arising out of the use of the Equipment. Further the Client will not use the Equipment nor permit it to be used in such a manner as would permit an insurer to decline any claim.

21.    Building and Construction Industry Security of Payments Act 1999

21.1    At the Supplier’s sole discretion, if there are any disputes or claims for unpaid Materials and/or Works then the provisions of the Building and Construction Industry Security of Payments Act 1999 may apply.
21.2    Nothing in this agreement is intended to have the affect of contracting out of any applicable provisions of the Building and Construction Industry Security of Payments Act 1999 of New South Wales, except to the extent permitted by the Act where applicable.

22.    General

22.1    The failure by the Supplier to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect the Supplier’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.
22.2    These terms and conditions and any contract to which they apply shall be governed by the laws of the state of New South Wales which the Supplier has its principal place of business, and are subject to the jurisdiction of the Newcastle Courts in that state.  
22.3    Subject to clause 13 the Supplier shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by the Supplier of these terms and conditions (alternatively the Supplier’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Materials/Equipment hire).
22.4    The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by the Supplier nor to withhold payment of any invoice because part of that invoice is in dispute.
22.5    The Supplier may license or sub-contract all or any part of its rights and obligations without the Client’s consent.
22.6    The Client agrees that the Supplier may amend these terms and conditions at any time. If the Supplier makes a change to these terms and conditions, then that change will take effect from the date on which the Supplier notifies the Client of such change. The Client will be taken to have accepted such changes if the Client makes a further request for the Supplier to provide Materials/Equipment to the Client.
22.7    Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.
22.8    The Client warrants that it has the power to enter into this agreement and has obtained all necessary authorisations to allow it to do so, it is not insolvent and that this agreement creates binding and valid legal obligations on it.